Effective Date: January 1, 2026
By accessing or using the website at wellingtonsunrooms.com, or by engaging Wellington Lanai Sunrooms & Patios ("Company," "we," "us," or "our") for any services, you agree to be bound by these Terms and Conditions. If you do not agree to these terms, please do not use our website or engage our services. These terms apply to all visitors, inquiry submitters, and customers.
Wellington Lanai Sunrooms & Patios is a sunroom contractor serving homeowners in Wellington, FL and surrounding Palm Beach County communities. Our services include sunroom additions, four season sunrooms, three season sunrooms, patio enclosures, screen room installation, patio-to-sunroom conversions, deck-to-sunroom conversions, solarium installation, patio cover installation, sunroom remodeling, and related design and construction services. All services are subject to a separate written contract executed before work begins.
Estimates provided by Wellington Lanai Sunrooms & Patios are based on an on-site assessment and the information you provide at the time of the estimate. Estimates are not guaranteed fixed prices unless they are incorporated into a signed written contract.
Final pricing may be adjusted if site conditions, material availability, scope changes, or permit requirements differ materially from the conditions assessed at the time of the estimate. We will notify you in writing of any scope or price change before proceeding with additional work. You have the right to approve or decline any change order before work continues.
Free estimates are provided at no obligation. Submitting a contact form or scheduling an estimate visit does not create a contractual obligation on either party.
Project start dates are scheduled based on permit approval timelines, material availability, and crew scheduling. Estimated start dates provided at the time of contract signing are good-faith estimates and may shift due to factors outside our control, including permit review delays by Palm Beach County, weather events, or material supply delays.
If you need to cancel or postpone a scheduled project, please notify us as soon as possible in writing. Cancellation terms, including any applicable deposits or fees, will be set out in your written contract. If a project is cancelled after materials have been ordered or fabricated specifically for your job, you may be responsible for costs already incurred, as described in the contract.
We reserve the right to postpone or suspend work due to unsafe conditions, including severe weather, active hurricane watches or warnings, or hazardous site conditions. We will notify you promptly and reschedule as soon as conditions allow.
Payment schedules are set out in your written contract. Typical projects are structured with a deposit at contract signing, a progress payment at a defined milestone (such as framing completion), and a final payment upon completion and your acceptance of the finished work.
Final payment is due upon project completion and final walkthrough, unless your contract specifies otherwise. Invoices not paid by the due date stated in the contract may be subject to late fees as described therein.
Under Florida law, we may have lien rights against your property for unpaid work. We will provide required notices in accordance with Florida Lien Law. Paying your contractor promptly and in accordance with your written contract is the best way to avoid any lien-related complications.
All construction work performed by Wellington Lanai Sunrooms & Patios is subject to applicable building codes and permit requirements in Palm Beach County, Florida. We pull all required permits on behalf of the customer and manage the inspection process as part of our standard service. Customers are responsible for obtaining any required HOA approvals before we apply for a permit. Delays caused by HOA review timelines or customer-side approval processes are not the responsibility of Wellington Lanai Sunrooms & Patios.
Any workmanship warranty provided by Wellington Lanai Sunrooms & Patios will be set out in your written contract. Warranties do not cover damage caused by acts of nature (including hurricanes and flooding), misuse, alterations by third parties, or failure to perform routine maintenance. Manufacturer warranties on materials and products pass through to the customer and are subject to the manufacturer's terms.
The website at wellingtonsunrooms.com and its content are provided "as is" without any warranty of accuracy, completeness, or fitness for a particular purpose. We make no warranty that general information on this website applies to your specific property, location, or project.
To the fullest extent permitted by applicable law, Wellington Lanai Sunrooms & Patios shall not be liable for any indirect, incidental, consequential, or punitive damages arising out of or related to services we provide or your use of this website. Our total liability to you for any claim arising out of a services contract shall not exceed the amount paid by you to us under that contract.
Nothing in these Terms and Conditions limits our liability for personal injury or property damage caused by our direct negligence, or any liability that cannot be excluded or limited under applicableFlorida law.
You may use our website for lawful purposes only. You may not use the site to transmit any harmful, illegal, or fraudulent content, or to attempt to gain unauthorized access to our systems or the systems of others. We reserve the right to block access to users who violate these terms.
All content on this website - including text, images, and design elements - is owned by or licensed to Wellington Lanai Sunrooms & Patios. You may not reproduce, copy, or distribute any content without our written permission.
If a dispute arises between you and Wellington Lanai Sunrooms & Patios related to services we have provided or this website, we encourage you to contact us directly first so we can try to resolve the issue informally. Most concerns can be resolved quickly with a straightforward conversation.
If informal resolution is not possible, any dispute shall be resolved through binding arbitration or litigation in a court of competent jurisdiction located in Palm Beach County, Florida, as set out in your written service contract. For website-only disputes not covered by a service contract, Palm Beach County, Florida shall be the exclusive venue.
These Terms and Conditions and any disputes arising under them shall be governed by and construed in accordance with the laws of the State of Florida, without regard to its conflict of law principles.
We may update these Terms and Conditions at any time by posting a revised version on this page with an updated effective date. Your continued use of our website after any changes constitutes your acceptance of the revised terms. Changes do not affect the terms of any written service contract already in effect between you andWellington Lanai Sunrooms & Patios.
If you have questions about these Terms and Conditions, contact us at:
Wellington Lanai Sunrooms & Patios
1340 Raintree Ln, Wellington, FL 33414
